Section § 7150

Explanation

This section defines two specific terms for the purposes of this law. First, it explains that 'person' refers only to actual human beings, not companies or organizations. Second, it states that a 'senior citizen' is someone who is 65 years old or older.

(a)CA Business & Professions Code § 7150(a) “Person” as used in this article is limited to natural persons, notwithstanding the definition of person in Section 7025.
(b)CA Business & Professions Code § 7150(b) “Senior citizen” means an individual who is 65 years of age or older.

Section § 7150.1

Explanation
This law defines a home improvement contractor, including those working on swimming pools, as someone licensed to do home improvement work, regardless of whether they do it full-time or part-time. These contractors must meet all the requirements outlined in this article.
A home improvement contractor, including a swimming pool contractor, is a contractor as defined and licensed under this chapter who is engaged in the business of home improvement either full time or part time. A home improvement contractor shall satisfy all requirements imposed by this article.

Section § 7151

Explanation

This law defines what "home improvement" means in terms of changes you might make to residential property. It covers a wide range of activities like repairing, remodeling, or adding new features to a home, especially when rebuilding after a disaster. It also clarifies what counts as "home improvement goods or services," such as installing air conditioning or termite extermination. Additionally, it specifies what qualifies as a "solar energy system," focusing on solar setups that convert sunlight into electricity for home use.

(a)CA Business & Professions Code § 7151(a) “Home improvement” means the repairing, remodeling, altering, converting, or modernizing of, or adding to, residential property, as well as the reconstruction, restoration, or rebuilding of a residential property that is damaged or destroyed by a natural disaster for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code, or for which an emergency or major disaster is declared by the President of the United States, and shall include, but not be limited to, the construction, erection, installation, replacement, or improvement of driveways, swimming pools, including spas and hot tubs, terraces, patios, awnings, storm windows, solar energy systems, landscaping, fences, porches, garages, fallout shelters, basements, and other improvements of the structures or land which is adjacent to a dwelling house. “Home improvement” shall also mean the installation of home improvement goods or the furnishing of home improvement services.
(b)CA Business & Professions Code § 7151(b) For purposes of this chapter, “home improvement goods or services” means goods and services, as defined in Section 1689.5 of the Civil Code, which are bought in connection with the improvement of real property. Such home improvement goods and services include, but are not limited to, carpeting, texture coating, fencing, air conditioning or heating equipment, and termite extermination. Home improvement goods include goods which are to be so affixed to real property as to become a part of real property whether or not severable therefrom.
(c)CA Business & Professions Code § 7151(c) For purposes of this article, “solar energy system” means a solar energy device to be installed on a residential building or residential property that has the primary purpose of providing for the collection and distribution of solar energy for the generation of electricity, that produces at least one kilowatt, and not more than five megawatts, alternating current rated peak electricity, and that meets or exceeds the eligibility criteria established pursuant to Section 25782 of the Public Resources Code.

Section § 7151.2

Explanation

This section defines a 'home improvement contract' as any agreement, whether spoken or written, between a contractor and a homeowner or tenant, or between a salesperson and a homeowner or tenant, that involves work or services to improve a home. This includes all labor, services, and materials for the improvement project, and it applies no matter how many units are in the building where the tenant lives.

“Home improvement contract” means an agreement, whether oral or written, or contained in one or more documents, between a contractor and an owner or between a contractor and a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, if the work is to be performed in, to, or upon the residence or dwelling unit of the tenant, for the performance of a home improvement as defined in Section 7151, and includes all labor, services, and materials to be furnished and performed thereunder. “Home improvement contract” also means an agreement, whether oral or written, or contained in one or more documents, between a salesperson, whether or not he or she is a home improvement salesperson, and (a) an owner or (b) a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, which provides for the sale, installation, or furnishing of home improvement goods or services.

Section § 7152

Explanation

This law explains what a 'home improvement salesperson' is and describes their registration requirements. These salespeople work for licensed contractors to sell or arrange home improvement services, like building pools or installing hot tubs. They must register with a board and can work for multiple contractors, but must always disclose which contractor they're representing in each transaction. Certain individuals, like corporate officers, general partners, or those involved in service repairs or retail transactions, do not need to register as long as they meet specific criteria.

(a)CA Business & Professions Code § 7152(a) “Home improvement salesperson” is a person who is registered under this chapter and engaged in the business of soliciting, selling, negotiating, or executing contracts for home improvements, for the sale, installation or furnishing of home improvement goods or services, or of swimming pools, spas, or hot tubs on behalf of a home improvement contractor licensed under this chapter.
(b)CA Business & Professions Code § 7152(b) A home improvement salesperson shall register with the board in order to engage in the business of, or act in the capacity of, a home improvement salesperson.
(c)CA Business & Professions Code § 7152(c) Subject to the provisions of Section 7154, a home improvement salesperson may be employed by one, or more than one, home improvement contractor. However, prior to engaging in any activity described in subdivision (a) of this section, a home improvement salesperson shall identify to the owner or tenant the business name and license number of the contractor they are representing for the purposes of that transaction. Failure to do so is a cause of disciplinary action within the meaning of Section 7155.
(d)CA Business & Professions Code § 7152(d) The following shall not be required to be registered as home improvement salespersons:
(1)CA Business & Professions Code § 7152(d)(1) An officer of record of a corporation licensed pursuant to this chapter, or a manager, member, or officer of record of a limited liability company licensed pursuant to this chapter.
(2)CA Business & Professions Code § 7152(d)(2) A general partner listed on the license record of a partnership licensed pursuant to this chapter.
(3)CA Business & Professions Code § 7152(d)(3) A qualifying person, as defined in Section 7025.
(4)CA Business & Professions Code § 7152(d)(4) A salesperson whose sales are all made pursuant to negotiations between the parties if the negotiations are initiated by the prospective buyer at or with a general merchandise retail establishment that operates from a fixed location where goods or services are offered for sale.
(5)CA Business & Professions Code § 7152(d)(5) A person who contacts the prospective buyer for the exclusive purpose of scheduling appointments for a registered home improvement salesperson.
(6)CA Business & Professions Code § 7152(d)(6) A bona fide service repairperson who is in the employ of a licensed contractor and whose repair or service call is limited to the service, repair, or emergency repair initially requested by the buyer of the service.
(e)CA Business & Professions Code § 7152(e) The exemption to registration provided under paragraphs (1), (2), and (3) of subdivision (c) shall apply only to those individuals who, at the time of the sales transaction, are listed as personnel of record for the licensee responsible for soliciting, negotiating, or contracting for a service or improvement that is subject to regulation under this article.

Section § 7153

Explanation

This law makes it illegal for someone to work as a home improvement salesperson in California without a proper registration. If you're caught doing this without the correct paperwork, it's considered a minor crime called a misdemeanor, and you could be fined or get a citation. Also, if a contractor tries to secure a payment through a security interest, this is invalid if the salesperson who set up the contract wasn't registered or exempt at the time the homeowner signed it.

(a)CA Business & Professions Code § 7153(a) It is a misdemeanor for any person to engage in the occupation of salesperson for one or more home improvement contractors within this state without having, at the time of the sales transaction, a current and valid home improvement salesperson registration issued by the registrar. If, upon investigation, the registrar has probable cause to believe that a salesperson is in violation of this section, the registrar may issue a citation pursuant to Section 7028.7.
It is a misdemeanor for any person to engage in the occupation of salesperson of home improvement goods or services within this state without having, at the time of the sales transaction, a current and valid home improvement salesperson registration issued by the registrar.
(b)CA Business & Professions Code § 7153(b) Any security interest taken by a contractor, to secure any payment for the performance of any act or conduct described in Section 7151 that occurs on or after January 1, 1995, is unenforceable if the person soliciting the act or contract was not a duly registered salesperson or was not exempt from registration pursuant to Section 7152 at the time the homeowner signs the home improvement contract solicited by the salesperson.

Section § 7153.1

Explanation

If you want to be registered as a home improvement salesperson, you must apply in writing, using a form and fee set by the registrar. They can deny your registration for specific reasons. You’ll also need to provide fingerprints for a background check, which can be submitted electronically if possible. The fingerprints help check your criminal history with state and federal agencies.

(a)CA Business & Professions Code § 7153.1(a) The home improvement salesperson shall submit to the registrar an application in writing containing the statement that he or she desires the issuance of a registration under the terms of this article.
The application shall be made on a form prescribed by the registrar and shall be accompanied by the fee fixed by this chapter.
(b)CA Business & Professions Code § 7153.1(b) The registrar may refuse to register the applicant under the grounds specified in Section 480.
(c)CA Business & Professions Code § 7153.1(c) As part of an application for a home improvement salesperson, the board shall require an applicant to furnish a full set of fingerprints for purposes of conducting criminal history record checks. Fingerprints furnished pursuant to this subdivision shall be submitted in an electronic format where readily available. Requests for alternative methods of furnishing fingerprints are subject to the approval of the registrar. The board shall use the fingerprints furnished by an applicant to obtain criminal history information on the applicant from the Department of Justice and the United States Federal Bureau of Investigation, including any subsequent arrest information available.

Section § 7153.2

Explanation

If you're a home improvement salesperson in California, your registration lasts for two years. It expires two years after the last day of the month it was first issued or two years after the last renewal date.

All home improvement salesperson registrations issued under the provisions of this article shall expire two years from the last day of the month in which the registration was issued, or two years from the date on which the renewed registration last expired.

Section § 7153.3

Explanation

If you're a registered home improvement salesperson in California, you need to renew your registration before it expires using a specific form and paying a renewal fee. If you miss the deadline, you have up to three years to renew, but you'll pay a penalty. After three years, you must reapply as if you're registering for the first time. If your renewal application is incomplete, it can be rejected, and if not corrected within 90 days, it will be considered abandoned. But, you can ask for reconsideration if there's a good reason for the delay, as long as you do so within 90 days of the notice. These rules have been in effect since July 1, 2017.

(a)CA Business & Professions Code § 7153.3(a) To renew a home improvement salesperson registration, which has not expired, the registrant shall before the time at which the registration would otherwise expire, apply for renewal on a form prescribed by the registrar and pay a renewal fee prescribed by this chapter. Renewal of an unexpired registration shall continue the registration in effect for the two-year period following the expiration date of the registration, when it shall expire if it is not again renewed.
(b)CA Business & Professions Code § 7153.3(b) An application for renewal of registration is delinquent if the application is not postmarked or received via electronic transmission as authorized by Section 7156.6 by the date on which the registration would otherwise expire. A registration may, however, still be renewed at any time within three years after its expiration upon the filing of an application for renewal on a form prescribed by the registrar and the payment of the renewal fee prescribed by this chapter and a delinquent renewal penalty equal to 50 percent of the renewal fee. If a registration is not renewed within three years, the person shall make a new application for registration pursuant to Section 7153.1.
(c)Copy CA Business & Professions Code § 7153.3(c)
(1)Copy CA Business & Professions Code § 7153.3(c)(1) The registrar may refuse to renew a registration for failure by the registrant to complete the application for renewal of registration. If a registrant fails to return the application rejected for insufficiency or incompleteness within 90 days from the original date of rejection, the application and fee shall be deemed abandoned. Any application abandoned may not be reinstated. However, the person may file a new application for registration pursuant to Section 7153.1.
(2)CA Business & Professions Code § 7153.3(c)(2) The registrar may review and accept the petition of a person who disputes the abandonment of his or her renewal application upon a showing of good cause. This petition shall be received within 90 days of the date the application for renewal is deemed abandoned.
(d)CA Business & Professions Code § 7153.3(d) This section shall become operative on July 1, 2017.

Section § 7154

Explanation

If you're a home improvement contractor in California, you need to officially inform the registrar in writing whenever you hire or let go of a registered home improvement salesperson. When you hire someone, you need to submit their name and registration number using a specific form before they start work. If someone stops working for you, you have 90 days to report that too. If you don't follow these rules, or if you hire someone who isn't registered, you could face disciplinary action.

(a)CA Business & Professions Code § 7154(a) A home improvement contractor licensed under this chapter shall notify the registrar in writing, on a form prescribed by the registrar, about the employment of a registered home improvement salesperson, pursuant to the terms of this article. This notification requirement shall include, but not be limited to, the name and registration number of the home improvement salesperson who is employed by the contractor. The form shall be submitted prior to the home improvement salesperson beginning work for the contractor.
(b)CA Business & Professions Code § 7154(b) A home improvement contractor shall notify the registrar in writing, on a form prescribed by the registrar, when a registered home improvement salesperson ceases to be employed by the contractor. This notification requirement shall include, but not be limited to, the name and registration number of the home improvement salesperson who had been employed by the contractor. The form shall be submitted within 90 days after the home improvement salesperson ceases to be employed by the contractor.
(c)CA Business & Professions Code § 7154(c) A home improvement contractor who employs a registered home improvement salesperson to sell home improvement contracts, but who fails to report to the registrar pursuant to subdivision (a) or (b), is subject to disciplinary action by the registrar.
(d)CA Business & Professions Code § 7154(d) A home improvement contractor who employs a person to sell home improvement contracts while that person is not registered by the registrar as a home improvement salesperson as provided in this article, is subject to disciplinary action by the registrar.

Section § 7155

Explanation

If a home improvement salesperson breaks any rules in this chapter, they can face disciplinary actions like having their registration suspended or revoked. The process for this discipline follows specific legal procedures outlined in a different part of government rules.

Violation of any provision of this chapter by a home improvement salesperson constitutes cause for disciplinary action. The registrar may suspend or revoke the registration of the home improvement salesperson if he or she is found to be in violation. The disciplinary proceedings shall be conducted in accordance with Chapter 5 (commencing with Section 11500) of Part 1 of Division 3 of Title 2 of the Government Code.

Section § 7155.5

Explanation

If a home improvement salesperson breaks any rules in this chapter, the contractor who employed them can also be disciplined. This applies even if the contractor wasn't aware of the violation or didn't take part in it.

Violations of any provisions of this chapter by a home improvement salesperson likewise constitute cause for disciplinary action against the contractor by whom he or she was employed at the time the violation occurred, whether or not the contractor had knowledge of or participated in the act or omission constituting violations of this chapter.

Section § 7156

Explanation

This law makes it a misdemeanor and a reason for disciplinary action for home improvement salespeople to do certain things. They can't keep money that should go to their contractor, use a contract form that doesn't include the contractor's name, or help choose a contractor if they haven't informed the Board of their employment.

It shall be a misdemeanor and a cause for disciplinary action to commit any of the following acts:
(a)CA Business & Professions Code § 7156(a) For any home improvement salesperson to fail to account for or to remit to their employing contractor any payment received in connection with any home improvement transaction or any other transaction involving a work of improvement.
(b)CA Business & Professions Code § 7156(b) For any person to use a contract form in connection with any home improvement transaction or any other transaction involving a work of improvement if the form fails to disclose the name of the contractor principal by whom the person is employed.
(c)CA Business & Professions Code § 7156(c) For any home improvement salesperson to assist, recommend, select, or otherwise guide an owner or tenant in the selection of a contractor for the performance or sale of home improvement goods or services if notification of employment by the home improvement contractor, as required by subdivision (a) of Section 7154, has not been received by the Board.

Section § 7156.6

Explanation
This law allows the board to use electronic systems for sending and receiving applications and notices related to registration that are required by this law. They can set up rules to make sure everything is secure and valid when done electronically. Once these rules are in place, doing everything online will count the same as doing it the old-fashioned way.
(a)CA Business & Professions Code § 7156.6(a) Notwithstanding any other law, the board may implement a system that provides for the electronic transmission of an initial application or renewal application for the registration required by this article and the electronic transmission of the notices required by Section 7154.
(b)CA Business & Professions Code § 7156.6(b) The board by regulation may specify the form and manner of these transmissions, including the adoption of any protocols necessary to ensure the validity and security of any information, data, or document transmitted electronically. Upon the effective date of the regulations, the electronic submission of an initial registration application, a renewal application, or the electronic transmission of a notice required by Section 7154 shall satisfy the requirements of this article.

Section § 7157

Explanation

This law outlines rules for contractors when offering home improvement contracts. Contractors can't offer rewards to customers for bringing them business. However, they can give promotional items, as long as the item is under $5 and isn’t linked to getting a contract. Salespeople and agents can't take or give money or gifts in a home improvement deal outside of their employer's payments. Contractors also can't pay or reward others for home improvement work unless that person is licensed or exempt from licensing. Violating these rules is a misdemeanor and can lead to disciplinary action. The term 'owners' includes tenants too.

(a)CA Business & Professions Code § 7157(a) Except as otherwise provided in subdivision (b), as a part of or in connection with the inducement to enter into any home improvement contract or other contract, which may be performed by a contractor, no person may promise or offer to pay, credit, or allow to any owner, compensation or reward for the procurement or placing of home improvement business with others.
(b)CA Business & Professions Code § 7157(b) A contractor or his or her agent or salesperson may give tangible items to prospective customers for advertising or sales promotion purposes where the gift is not conditioned upon obtaining a contract for home improvement work if the gift does not exceed a value of five dollars ($5) and only one such gift is given in connection with any one transaction.
(c)CA Business & Professions Code § 7157(c) No salesperson or contractor’s agent may accept any compensation of any kind, for or on account of a home improvement transaction, or any other transaction involving a work of improvement, from any person other than the contractor whom he or she represents with respect to the transaction, nor shall the salesperson or agent make any payment to any person other than his or her employer on account of the sales transaction.
(d)CA Business & Professions Code § 7157(d) No contractor shall pay, credit, or allow any consideration or compensation of any kind to any other contractor or salesperson other than a licensee for or on account of the performance of any work of improvement or services, including, but not limited to, home improvement work or services, except: (1) where the person to or from whom the consideration is to be paid is not subject to or is exempted from the licensing requirements of this chapter, or (2) where the transaction is not subject to the requirements of this chapter.
As used in this section “owners” shall also mean “tenant.”
Commission of any act prohibited by this section is a misdemeanor and constitutes a cause for disciplinary action.

Section § 7158

Explanation
This law makes it illegal to falsely claim that a construction or home improvement project is finished if you know it's not, and then try to use that false document to get paid or secure a loan. If you're caught doing this, you could face jail time, a fine, or both. If this is part of a scheme to defraud someone due to a natural disaster, the law requires you to repay the victim. Additionally, you might face higher fines based on what you can afford to pay. This regulation is particularly strict if the fraudulent activity occurs during state or federally declared emergencies.
(a)CA Business & Professions Code § 7158(a) Any person who shall accept or receive a completion certificate or other evidence that performance of a contract for a work of improvement, including, but not limited to, a home improvement, is complete or satisfactorily concluded, with knowledge that the document is false and that the performance is not substantially completed, and who shall utter, offer, or use the document in connection with the making or accepting of any assignment or negotiation of the right to receive any payment from the owner, under or in connection with a contract, or for the purpose of obtaining or granting any credit or loan on the security of the right to receive any payment shall be guilty of a misdemeanor and subject to a fine of not less than five hundred dollars ($500) nor more than five thousand dollars ($5,000), or to imprisonment in the county jail for a term of not less than one month nor more than one year, or both.
(b)Copy CA Business & Professions Code § 7158(b)
(1)Copy CA Business & Professions Code § 7158(b)(1) Any person who violates this section as part of a plan or scheme to defraud an owner of a residential or nonresidential structure, including a mobilehome or manufactured home, in connection with the offer or performance of repairs to the structure for damage caused by a natural disaster, shall be ordered by the court to make full restitution to the victim based on the person’s ability to pay, defined as the overall capability of the defendant to reimburse the costs, or a portion of the costs, including consideration of, but not limited to, all of the following:
(A)CA Business & Professions Code § 7158(b)(1)(A) The defendant’s present financial position.
(B)CA Business & Professions Code § 7158(b)(1)(B) The defendant’s reasonably discernible future financial position, provided that the court shall not consider a period of more than one year from the date of the hearing for purposes of determining the reasonably discernible future financial position of the defendant.
(C)CA Business & Professions Code § 7158(b)(1)(C) The likelihood that the defendant will be able to obtain employment within one year from the date of the hearing.
(D)CA Business & Professions Code § 7158(b)(1)(D) Any other factor that may bear upon the defendant’s financial capability to reimburse the county for costs.
(2)CA Business & Professions Code § 7158(b)(2) In addition to full restitution, and imprisonment authorized by subdivision (a), the court may impose a fine of not less than five hundred dollars ($500) nor more than twenty-five thousand dollars ($25,000), based upon the defendant’s ability to pay. This subdivision applies to natural disasters for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code or for which an emergency or major disaster is declared by the President of the United States.
(c)CA Business & Professions Code § 7158(c) This section shall become operative on July 1, 2021.

Section § 7159

Explanation

This law sets the rules for home improvement contracts that cost over $500. It's about what needs to be in the contract, like details of the work, pricing, and payment schedule. The contract must be clear and readable, and you must provide a copy to the buyer before starting any work. Homeowners have the right to a written 'Notice of Cancellation' and can back out of the contract within three days, or seven if there's an emergency. Contractors need to present notices about insurance and workers' compensation, and they must not collect money for work or materials not yet delivered. If contractors mess up any part of these rules, they might face penalties.

(a)Copy CA Business & Professions Code § 7159(a)
(1)Copy CA Business & Professions Code § 7159(a)(1) This section identifies the projects for which a home improvement contract is required, outlines the contract requirements, and lists the items that shall be included in the contract, or may be provided as an attachment.
(2)CA Business & Professions Code § 7159(a)(2) This section does not apply to service and repair contracts that are subject to Section 7159.10, if the contract for the applicable services complies with Sections 7159.10 to 7159.14, inclusive.
(3)CA Business & Professions Code § 7159(a)(3) This section does not apply to the sale, installation, and servicing of a fire alarm sold in conjunction with an alarm system, as defined in Section 7590.1, if all costs attributable to making the fire alarm system operable, including sale and installation costs, do not exceed five hundred dollars ($500), and the licensee complies with the requirements set forth in Section 7159.9.
(4)CA Business & Professions Code § 7159(a)(4) This section does not apply to any costs associated with monitoring a burglar or fire alarm system.
(5)CA Business & Professions Code § 7159(a)(5) Failure by the licensee, their agent or salesperson, or by a person subject to be licensed under this chapter, to provide the specified information, notices, and disclosures in the contract, or to otherwise fail to comply with any provision of this section, is cause for discipline.
(b)CA Business & Professions Code § 7159(b) For purposes of this section, “home improvement contract” means an agreement, whether oral or written, or contained in one or more documents, between a contractor and an owner or between a contractor and a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, if the work is to be performed in, to, or upon the residence or dwelling unit of the tenant, for the performance of a home improvement, as defined in Section 7151, and includes all labor, services, and materials to be furnished and performed thereunder, if the aggregate contract price specified in one or more improvement contracts, including all labor, services, and materials to be furnished by the contractor, exceeds five hundred dollars ($500). “Home improvement contract” also means an agreement, whether oral or written, or contained in one or more documents, between a salesperson, whether or not they are a home improvement salesperson, and an owner or a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, which provides for the sale, installation, or furnishing of home improvement goods or services.
(c)CA Business & Professions Code § 7159(c) In addition to the specific requirements listed under this section, every home improvement contract and any person subject to licensure under this chapter or their agent or salesperson shall comply with all of the following:
(1)CA Business & Professions Code § 7159(c)(1) The writing shall be legible.
(2)CA Business & Professions Code § 7159(c)(2) Any printed form shall be readable. Unless a larger typeface is specified in this article, text in any printed form shall be in at least 10-point typeface and the headings shall be in at least 10-point boldface type.
(3)Copy CA Business & Professions Code § 7159(c)(3)
(A)Copy CA Business & Professions Code § 7159(c)(3)(A) Before any work is started, the contractor shall give the buyer a copy of the contract signed and dated by both the contractor and the buyer. The buyer’s receipt of the copy of the contract initiates the buyer’s rights to cancel the contract pursuant to Sections 1689.5 to 1689.14, inclusive, of the Civil Code.
(B)CA Business & Professions Code § 7159(c)(3)(A)(B) The contract shall contain on the first page, in a typeface no smaller than that generally used in the body of the document, both of the following:
(i)CA Business & Professions Code § 7159(c)(3)(A)(B)(i) The date the buyer signed the contract.
(ii)CA Business & Professions Code § 7159(c)(3)(A)(B)(ii) The name and address of the contractor to which the applicable “Notice of Cancellation” is to be mailed, immediately preceded by a statement advising the buyer that the “Notice of Cancellation” may be sent to the contractor at the address noted on the contract.
(4)CA Business & Professions Code § 7159(c)(4) The contract shall include a statement that, upon satisfactory payment being made for any portion of the work performed, the contractor, prior to any further payment being made, shall furnish to the person contracting for the home improvement or swimming pool work a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for that portion of the work for which payment has been made.
(5)CA Business & Professions Code § 7159(c)(5) A change-order form for changes or extra work shall be incorporated into the contract and shall become part of the contract only if it is in writing and signed by the parties prior to the commencement of any work covered by a change order.
(6)CA Business & Professions Code § 7159(c)(6) The contract shall contain, in close proximity to the signatures of the owner and contractor, a notice stating that the owner or tenant has the right to require the contractor to have a performance and payment bond.
(7)CA Business & Professions Code § 7159(c)(7) If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control.
(8)CA Business & Professions Code § 7159(c)(8) The provisions of this section are not exclusive and do not relieve the contractor from compliance with any other applicable provision of law.
(d)CA Business & Professions Code § 7159(d) A home improvement contract and any changes to the contract shall be in writing and signed by the parties to the contract prior to the commencement of work covered by the contract or an applicable change order and, except as provided in paragraph (8) of subdivision (a) of Section 7159.5, shall include or comply with all of the following:
(1)CA Business & Professions Code § 7159(d)(1) The name, business address, and license number of the contractor.
(2)CA Business & Professions Code § 7159(d)(2) If applicable, the name and registration number of the home improvement salesperson that solicited or negotiated the contract.
(3)CA Business & Professions Code § 7159(d)(3) The following heading on the contract form that identifies the type of contract in at least 10-point boldface type: “Home Improvement.”
(4)CA Business & Professions Code § 7159(d)(4) The following statement in at least 12-point boldface type: “You are entitled to a completely filled in copy of this agreement, signed by both you and the contractor, before any work may be started.”
(5)CA Business & Professions Code § 7159(d)(5) The heading: “Contract Price,” followed by the amount of the contract in dollars and cents.
(6)CA Business & Professions Code § 7159(d)(6) If a finance charge will be charged, the heading: “Finance Charge,” followed by the amount in dollars and cents. The finance charge is to be set out separately from the contract amount.
(7)CA Business & Professions Code § 7159(d)(7) The heading: “Description of the Project and Description of the Significant Materials to be Used and Equipment to be Installed,” followed by a description of the project and a description of the significant materials to be used and equipment to be installed. For swimming pools, the project description required under this paragraph also shall include a plan and scale drawing showing the shape, size, dimensions, and the construction and equipment specifications.
(8)CA Business & Professions Code § 7159(d)(8) If a downpayment will be charged, the details of the downpayment shall be expressed in substantially the following form, and shall include the text of the notice as specified in subparagraph (C):
(A)CA Business & Professions Code § 7159(d)(8)(A) The heading: “Downpayment.”
(B)CA Business & Professions Code § 7159(d)(8)(B) A space where the actual downpayment appears.
(C)CA Business & Professions Code § 7159(d)(8)(C) The following statement in at least 12-point boldface type:
“THE DOWNPAYMENT MAY NOT EXCEED $1,000 OR 10 PERCENT OF THE CONTRACT PRICE, WHICHEVER IS LESS.”
(9)CA Business & Professions Code § 7159(9) If payments, other than the downpayment, are to be made before the project is completed, the details of these payments, known as progress payments, shall be expressed in substantially the following form, and shall include the text of the statement as specified in subparagraph (C):
(A)CA Business & Professions Code § 7159(9)(A) A schedule of progress payments shall be preceded by the heading: “Schedule of Progress Payments.”
(B)CA Business & Professions Code § 7159(9)(B) Each progress payment shall be stated in dollars and cents and specifically reference the amount of work or services to be performed and materials and equipment to be supplied.
(C)CA Business & Professions Code § 7159(9)(C) The section of the contract reserved for the progress payments shall include the following statement in at least 12-point boldface type:
“The schedule of progress payments must specifically describe each phase of work, including the type and amount of work or services scheduled to be supplied in each phase, along with the amount of each proposed progress payment. IT IS AGAINST THE LAW FOR A CONTRACTOR TO COLLECT PAYMENT FOR WORK NOT YET COMPLETED, OR FOR MATERIALS NOT YET DELIVERED. HOWEVER, A CONTRACTOR MAY REQUIRE A DOWNPAYMENT.”
(10)CA Business & Professions Code § 7159(10) The contract shall address the commencement of work to be performed in substantially the following form:
(A)CA Business & Professions Code § 7159(10)(A) A statement that describes what constitutes substantial commencement of work under the contract.
(B)CA Business & Professions Code § 7159(10)(B) The heading: “Approximate Start Date.”
(C)CA Business & Professions Code § 7159(10)(C) The approximate date on which work will be commenced.
(11)CA Business & Professions Code § 7159(11) The estimated completion date of the work shall be referenced in the contract in substantially the following form:
(A)CA Business & Professions Code § 7159(11)(A) The heading: “Approximate Completion Date.”
(B)CA Business & Professions Code § 7159(11)(B) The approximate date of completion.
(12)CA Business & Professions Code § 7159(12) If applicable, the heading: “List of Documents to be Incorporated into the Contract,” followed by the list of documents incorporated into the contract.
(13)CA Business & Professions Code § 7159(13) The heading: “Note About Extra Work and Change Orders,” followed by the following statement:
“Extra Work and Change Orders become part of the contract once the order is prepared in writing and signed by the parties prior to the commencement of work covered by the new change order. The order must describe the scope of the extra work or change, the cost to be added or subtracted from the contract, and the effect the order will have on the schedule of progress payments.”
(e)CA Business & Professions Code § 7159(e) Except as provided in paragraph (8) of subdivision (a) of Section 7159.5, all of the following notices shall be provided to the owner as part of the contract form as specified or, if otherwise authorized under this subdivision, may be provided as an attachment to the contract:
(1)CA Business & Professions Code § 7159(e)(1) A notice concerning commercial general liability insurance. This notice may be provided as an attachment to the contract if the contract includes the following statement: “A notice concerning commercial general liability insurance is attached to this contract.” The notice shall include the heading “Commercial General Liability Insurance (CGL),” followed by whichever of the following statements is both relevant and correct:
(A)CA Business & Professions Code § 7159(e)(1)(A) “(The name on the license or ‛This contractor’) does not carry commercial general liability insurance.”
(B)CA Business & Professions Code § 7159(e)(1)(B) “(The name on the license or ‛This contractor’) carries commercial general liability insurance written by (the insurance company). You may call (the insurance company) at __________ to check the contractor’s insurance coverage.”
(C)CA Business & Professions Code § 7159(e)(1)(C) “(The name on the license or ‛This contractor’) is self-insured.”
(D)CA Business & Professions Code § 7159(e)(1)(D) “(The name on the license or ‘This contractor’) is a limited liability company that carries liability insurance or maintains other security as required by law. You may call (the insurance company or trust company or bank) at ____ to check on the contractor’s insurance coverage or security.”
(2)CA Business & Professions Code § 7159(e)(2) A notice concerning workers’ compensation insurance. This notice may be provided as an attachment to the contract if the contract includes the statement: “A notice concerning workers’ compensation insurance is attached to this contract.” The notice shall include the heading “Workers’ Compensation Insurance” followed by whichever of the following statements is correct:
(A)CA Business & Professions Code § 7159(e)(2)(A) “(The name on the license or ‛This contractor’) has no employees and is exempt from workers’ compensation requirements.”
(B)CA Business & Professions Code § 7159(e)(2)(B) “(The name on the license or ‛This contractor’) carries workers’ compensation insurance for all employees.”
(3)CA Business & Professions Code § 7159(e)(3) A notice that provides the buyer with the following information about the performance of extra or change-order work:
(A)CA Business & Professions Code § 7159(e)(3)(A) A statement that the buyer may not require a contractor to perform extra or change-order work without providing written authorization prior to the commencement of work covered by the new change order.
(B)CA Business & Professions Code § 7159(e)(3)(B) A statement informing the buyer that extra work or a change order is not enforceable against a buyer unless the change order also identifies all of the following in writing prior to the commencement of work covered by the new change order:
(i)CA Business & Professions Code § 7159(e)(3)(B)(i) The scope of work encompassed by the order.
(ii)CA Business & Professions Code § 7159(e)(3)(B)(ii) The amount to be added or subtracted from the contract.
(iii)CA Business & Professions Code § 7159(e)(3)(B)(iii) The effect the order will make in the progress payments or the completion date.
(C)CA Business & Professions Code § 7159(e)(3)(C) A statement informing the buyer that the contractor’s failure to comply with the requirements of this paragraph does not preclude the recovery of compensation for work performed based upon legal or equitable remedies designed to prevent unjust enrichment.
(4)CA Business & Professions Code § 7159(e)(4) A notice with the heading “Mechanics Lien Warning” written as follows:
“MECHANICS LIEN WARNING:
Anyone who helps improve your property, but who is not paid, may record what is called a mechanics lien on your property. A mechanics lien is a claim, like a mortgage or home equity loan, made against your property and recorded with the county recorder.
Even if you pay your contractor in full, unpaid subcontractors, suppliers, and laborers who helped to improve your property may record mechanics liens and sue you in court to foreclose the lien. If a court finds the lien is valid, you could be forced to pay twice or have a court officer sell your home to pay the lien. Liens can also affect your credit.
To preserve their right to record a lien, each subcontractor and material supplier must provide you with a document called a ‘Preliminary Notice.’ This notice is not a lien. The purpose of the notice is to let you know that the person who sends you the notice has the right to record a lien on your property if they are not paid.
BE CAREFUL.  The Preliminary Notice can be sent up to 20 days after the subcontractor starts work or the supplier provides material. This can be a big problem if you pay your contractor before you have received the Preliminary Notices.
You will not get Preliminary Notices from your prime contractor or from laborers who work on your project. The law assumes that you already know they are improving your property.
PROTECT YOURSELF FROM LIENS.  You can protect yourself from liens by getting a list from your contractor of all the subcontractors and material suppliers that work on your project. Find out from your contractor when these subcontractors started work and when these suppliers delivered goods or materials. Then wait 20 days, paying attention to the Preliminary Notices you receive.
PAY WITH JOINT CHECKS.  One way to protect yourself is to pay with a joint check. When your contractor tells you it is time to pay for the work of a subcontractor or supplier who has provided you with a Preliminary Notice, write a joint check payable to both the contractor and the subcontractor or material supplier.
For other ways to prevent liens, visit CSLB’s internet website at www.cslb.ca.gov or call CSLB at 800-321-CSLB (2752).
REMEMBER, IF YOU DO NOTHING, YOU RISK HAVING A LIEN PLACED ON YOUR HOME. This can mean that you may have to pay twice, or face the forced sale of your home to pay what you owe.”
(5)CA Business & Professions Code § 7159(5) The following notice shall be provided in at least 12-point typeface:
“Information about the Contractors State License Board (CSLB): CSLB is the state consumer protection agency that licenses and regulates construction contractors.
Contact CSLB for information about the licensed contractor you are considering, including information about disclosable complaints, disciplinary actions, and civil judgments that are reported to CSLB.
Use only licensed contractors. If you file a complaint against a licensed contractor within the legal deadline (usually four years), CSLB has authority to investigate the complaint. If you use an unlicensed contractor, CSLB may not be able to help you resolve your complaint. Your only remedy may be in civil court, and you may be liable for damages arising out of any injuries to the unlicensed contractor or the unlicensed contractor’s employees.
For more information:
Visit CSLB’s internet website at www.cslb.ca.gov
Call CSLB at 800-321-CSLB (2752)
Write CSLB at P.O. Box 26000, Sacramento, CA 95826.”
(6)Copy CA Business & Professions Code § 7159(6)
(A)Copy CA Business & Professions Code § 7159(6)(A) The notice set forth in subparagraph (B) and entitled “Three-Day Right to Cancel,” or entitled “Five-Day Right to Cancel” for contracts with a senior citizen, shall be provided to the buyer unless the contract is:
(i)CA Business & Professions Code § 7159(6)(A)(i) Negotiated at the contractor’s place of business.
(ii)CA Business & Professions Code § 7159(6)(A)(ii) Subject to the “Seven-Day Right to Cancel,” as set forth in paragraph (7).
(iii)CA Business & Professions Code § 7159(6)(A)(iii) Subject to licensure under the Alarm Company Act (Chapter 11.6 (commencing with Section 7590)), provided the alarm company licensee complies with Sections 1689.5, 1689.6, and 1689.7 of the Civil Code, as applicable.
(B)Copy CA Business & Professions Code § 7159(6)(A)(B)
(i)Copy CA Business & Professions Code § 7159(6)(A)(B)(i) “Three-Day Right to Cancel
You, the buyer, have the right to cancel this contract within three business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractor’s place of business by midnight of the third business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.
If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractor’s instructions on how to return the goods at the contractor’s expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.”
(ii)CA Business & Professions Code § 7159(ii) References to “three” and “third” in the notice set forth in clause (i) shall be changed to “five” and “fifth,” respectively, for a buyer who is a senior citizen.
(C)CA Business & Professions Code § 7159(C) The notice required by this paragraph shall comply with all of the following:
(i)CA Business & Professions Code § 7159(C)(i) The text of the notice is at least 12-point boldface type.
(ii)CA Business & Professions Code § 7159(C)(ii) The notice is in immediate proximity to a space reserved for the owner’s signature.
(iii)CA Business & Professions Code § 7159(C)(iii) The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.
(iv)CA Business & Professions Code § 7159(C)(iv) The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.
(v)CA Business & Professions Code § 7159(C)(v) The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with one of the following statements, as applicable:
(I)CA Business & Professions Code § 7159(C)(v)(I) For a contract with a senior citizen: “The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a ‛Notice of the Five-Day Right to Cancel.’ ”
(II) For all other contracts: “The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a ‛Notice of the Three-Day Right to Cancel.’”
(vi)Copy CA Business & Professions Code § 7159(C)(vi)
(I)Copy CA Business & Professions Code § 7159(C)(vi)(I) The notice shall be accompanied by a completed form in duplicate, captioned “Notice of Cancellation,” which also shall be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:
“Notice of Cancellation”
/enter date of transaction/
(Date)
“You may cancel this transaction, without any penalty or obligation, within three business days from the above date.
If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.
If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the seller’s expense and risk.
If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.”
To cancel this transaction, mail or deliver a signed and dated copy of this cancellation notice, or any other written notice, or send a telegram
to ,
/name of seller/
at
/address of seller’s place of business/
not later than midnight of .
(Date)
I hereby cancel this transaction.
(Date)
(Buyer’s signature)
(II) The reference to “three” in the statement set forth in subclause (I) shall be changed to “five” for a buyer who is a senior citizen.
(7)Copy CA Business & Professions Code § 7159(7)
(A)Copy CA Business & Professions Code § 7159(7)(A) The following notice entitled “Seven-Day Right to Cancel” shall be provided to the buyer for any contract that is written for the repair or restoration of residential premises damaged by any sudden or catastrophic event for which a state of emergency has been declared by the President of the United States or the Governor, or for which a local emergency has been declared by the executive officer or governing body of any city, county, or city and county:
“Seven-Day Right to Cancel
You, the buyer, have the right to cancel this contract within seven business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractor’s place of business by midnight of the seventh business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.
If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractor’s instructions on how to return the goods at the contractor’s expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.”
(B)CA Business & Professions Code § 7159(B) The “Seven-Day Right to Cancel” notice required by this subdivision shall comply with all of the following:
(i)CA Business & Professions Code § 7159(B)(i) The text of the notice is at least 12-point boldface type.
(ii)CA Business & Professions Code § 7159(B)(ii) The notice is in immediate proximity to a space reserved for the owner’s signature.
(iii)CA Business & Professions Code § 7159(B)(iii) The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.
(iv)CA Business & Professions Code § 7159(B)(iv) The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.
(v)CA Business & Professions Code § 7159(B)(v) The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with the following statement: “The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a ‛Notice of the Seven-Day Right to Cancel.’ ”
(vi)CA Business & Professions Code § 7159(B)(vi) The notice shall be accompanied by a completed form in duplicate, captioned “Notice of Cancellation,” which shall also be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:
“Notice of Cancellation”
/enter date of transaction/
(Date)
“You may cancel this transaction, without any penalty or obligation, within seven business days from the above date.
If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.
If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the seller’s expense and risk.
If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.”
To cancel this transaction, mail or deliver a signed and dated copy of this cancellation notice, or any other written notice, or send a telegram
to ,
/name of seller/
at
/address of seller’s place of business/
not later than midnight of .
(Date)
I hereby cancel this transaction.
(Date)
(Buyer’s signature)
(f)CA Business & Professions Code § 7159(f) The five-day right to cancel added by the act that amended paragraph (6) of subdivision (e) shall apply to contracts entered into on or after January 1, 2021.

Section § 7159.1

Explanation

This law requires that when you sign a contract for home improvement services sold door-to-door and the contract might use your home as collateral, there has to be a clear warning notice in large, bold print. This notice warns that you could lose your home without a court process if you miss any payments. This warning must be in the same language as the contract, on a separate paper, signed, and a copy given to you by the salesperson. If the contract doesn't follow these rules, it's not legally enforceable. However, this requirement doesn't apply to certain contracts covered by specific sections of the Civil Code or mechanics liens.

(a)CA Business & Professions Code § 7159.1(a) In any contract for the sale of home improvement goods or services offered by door-to-door sale that contains or is secured by a lien on real property, the contract shall be accompanied by the following notice in 18-point boldfaced type:
“WARNING TO BUYER: IF YOU SIGN THE CONTRACT WHICH ACCOMPANIES THIS NOTICE, YOU WILL BE PUTTING UP YOUR HOME AS SECURITY. THIS MEANS THAT YOUR HOME COULD BE SOLD WITHOUT YOUR PERMISSION AND WITHOUT ANY COURT ACTION IF YOU MISS ANY PAYMENT REQUIRED BY THIS CONTRACT.”
This notice shall be written in the same language as the rest of the contract. It shall be on a separate piece of paper from the rest of the contract and shall be signed and dated by the buyer. The home improvement contractor or home improvement salesperson shall deliver to the buyer at the time of the buyer’s signing and dating of the notice a legible copy of the signed and dated notice. A security interest created in any contract described in this section that does not provide the notice as required by this section shall be void and unenforceable.
(b)CA Business & Professions Code § 7159.1(b) This section shall not apply to any of the following:
(1)CA Business & Professions Code § 7159.1(b)(1) Any contract that is subject to Chapter 1 (commencing with Section 1801) of Title 2 of Part 4 of Division 3 of the Civil Code.
(2)CA Business & Professions Code § 7159.1(b)(2) A mechanics lien established pursuant to Chapter 4 (commencing with Section 8400) of Title 2 of Part 6 of Division 4 of the Civil Code.
(3)CA Business & Professions Code § 7159.1(b)(3) Any contract that is subject to subdivision (a) of Section 7159.2.

Section § 7159.10

Explanation

This law defines what a 'service and repair contract' is in the context of home improvement work performed by licensed contractors. To qualify, such contracts must be for no more than $750, initiated by the homeowner, and include only necessary services. Contractors can only be paid after completing the work, which includes passing any required inspections. The contract must be in writing, signed, and understood by the homeowner, with specific notices about rights and insurance. Homeowners can cancel contracts under specific conditions, such as if they didn't initiate contact or if unnecessary services were added. The law also outlines the required format and disclosures for these contracts, including how to cancel them and procedures if you're a senior citizen or affected by a declared emergency.

(a)Copy CA Business & Professions Code § 7159.10(a)
(1)Copy CA Business & Professions Code § 7159.10(a)(1) “Service and repair contract” means an agreement between a contractor or salesperson for a contractor, whether a general contractor or a specialty contractor, who is licensed or subject to be licensed pursuant to this chapter with regard to the transaction, and a homeowner or a tenant, for the performance of a home improvement as defined in Section 7151, that conforms to the following requirements:
(A)CA Business & Professions Code § 7159.10(a)(1)(A) The contract amount is seven hundred fifty dollars ($750) or less.
(B)CA Business & Professions Code § 7159.10(a)(1)(B) The prospective buyer initiated contact with the contractor to request the work.
(C)CA Business & Professions Code § 7159.10(a)(1)(C) The contractor does not sell the buyer goods or services beyond those reasonably necessary to take care of the particular problem that caused the buyer to contact the contractor.
(D)CA Business & Professions Code § 7159.10(a)(1)(D) No payment is due, or accepted by the contractor, until the work is completed.
(2)CA Business & Professions Code § 7159.10(a)(2) As used in this subdivision, “the work is completed” means that all of the conditions that caused the buyer to contact the contractor for service and repairs have been fully corrected and, if applicable, the building department has accepted and approved the corrective work.
(b)CA Business & Professions Code § 7159.10(b) For any contract written pursuant to subdivision (a) or otherwise presented to the buyer as a service and repair contract, unless all of the conforming requirements for service and repair contracts specified in subdivision (a) are met, the contract requirements for home improvements set forth in subdivisions (c), (d), and (e) of Section 7159 shall be applicable, including any rights to rescind the contract as set forth in Section 1689.6 or 1689.7 of the Civil Code, regardless of the aggregate contract price.
(c)CA Business & Professions Code § 7159.10(c) If all of the requirements of subdivision (a) are met, only those notices and other requirements set forth in this section are applicable to the contract.
(d)CA Business & Professions Code § 7159.10(d) Every service and repair contract described in subdivision (a) shall include, or otherwise comply with, all of the following:
(1)CA Business & Professions Code § 7159.10(d)(1) The contract, any changes to the contract, and any attachments shall be in writing and signed or acknowledged by the parties as set forth in this section, and shall be written in the same language (for example Spanish) as principally used in the oral sales presentation.
(2)CA Business & Professions Code § 7159.10(d)(2) The writing shall be legible.
(3)CA Business & Professions Code § 7159.10(d)(3) Any printed form shall be readable. Unless a larger typeface is specified in this article, the text shall be in at least 10-point typeface and the headings shall be in at least 10-point boldface type.
(4)CA Business & Professions Code § 7159.10(d)(4) Before any work is started, the contractor shall give the buyer a copy of the contract signed and dated by the buyer and by the contractor or the contractor’s representative.
(5)CA Business & Professions Code § 7159.10(d)(5) The name, business address, and license number of the contractor.
(6)CA Business & Professions Code § 7159.10(d)(6) The date the contract was signed.
(7)CA Business & Professions Code § 7159.10(d)(7) A notice concerning commercial general liability insurance. This notice may be provided as an attachment to the contract if the contract includes the statement, “A notice concerning commercial general liability insurance is attached to this contract.” The notice shall include the heading “Commercial General Liability Insurance (CGL)” followed by whichever of the following statements is both relevant and correct:
(A)CA Business & Professions Code § 7159.10(d)(7)(A) “(The name on the license or ‘This contractor’) does not carry commercial general liability insurance.”
(B)CA Business & Professions Code § 7159.10(d)(7)(B) “(The name on the license or ‘This contractor’) carries commercial general liability insurance written by (the insurance company). You may call the (insurance company) at ____ to check the contractor’s insurance coverage.”
(C)CA Business & Professions Code § 7159.10(d)(7)(C) “(The name on the license or ‘This contractor’) is self-insured.”
(D)CA Business & Professions Code § 7159.10(d)(7)(D) “(The name on the license or ‘This contractor’) is a limited liability company that carries liability insurance or maintains other security as required by law. You may call (the insurance company or trust company or bank) at ____ to check on the contractor’s insurance coverage or security.”
(8)CA Business & Professions Code § 7159.10(d)(8) A notice concerning workers’ compensation insurance. This notice may be provided as an attachment to the contract if the contract includes the statement “A notice concerning workers’ compensation insurance is attached to this contract.” The notice shall include the heading “Workers’ Compensation Insurance” followed by whichever of the following statements is both relevant and correct:
(A)CA Business & Professions Code § 7159.10(d)(8)(A) “(The name on the license or ‘This contractor’) has no employees and is exempt from workers’ compensation requirements.”
(B)CA Business & Professions Code § 7159.10(d)(8)(B) “(The name on the license or ‘This contractor’) carries workers’ compensation insurance for all employees.”
(e)CA Business & Professions Code § 7159.10(e) Every service and repair contract described in subdivision (a) shall provide the following information, notices, and disclosures in the contract:
(1)CA Business & Professions Code § 7159.10(e)(1) Notice of the type of contract in at least 10-point boldface type: “Service and Repair.”
(2)CA Business & Professions Code § 7159.10(e)(2) A notice in at least 12-point boldface type, signed and dated by the buyer: “Notice to the Buyer: The law requires that service and repair contracts must meet all of the following requirements:
(A)CA Business & Professions Code § 7159.10(e)(2)(A) The price must be no more than seven hundred and fifty dollars ($750).
(B)CA Business & Professions Code § 7159.10(e)(2)(B) You, the buyer, must have initiated contact with the contractor to request the work.
(C)CA Business & Professions Code § 7159.10(e)(2)(C) The contractor must not sell you goods or services beyond those reasonably necessary to take care of the particular problem that caused you to contact the contractor.
(D)CA Business & Professions Code § 7159.10(e)(2)(D) No payment is due and the contractor may not accept any payment until the work is completed.”
(3)CA Business & Professions Code § 7159.10(e)(3) The notice in at least 12-point boldface type: “Notice to the Buyer: You are entitled to a completely filled in and signed copy of this agreement before any work may be started.”
(4)CA Business & Professions Code § 7159.10(e)(4) If applicable, the heading “List of Documents to be Incorporated into the Contract,” followed by the list of documents to be incorporated into the contract.
(5)CA Business & Professions Code § 7159.10(e)(5) Where the contract is a fixed contract amount, the heading: “Contract Price” followed by the amount of the contract in dollars and cents.
(6)CA Business & Professions Code § 7159.10(e)(6) If a finance charge will be charged, the heading: “Finance Charge” followed by the amount in dollars and cents. The finance charge is to be set out separately from the contract amount.
(7)CA Business & Professions Code § 7159.10(e)(7) Where the contract is estimated by a time and materials formula, the heading “Estimated Contract Price” followed by the estimated contract amount in dollars and cents. The contract must disclose the set rate and the estimated cost of materials. The contract must also disclose how time will be computed, for example, in increments of quarter hours, half hours, or hours, and the statement: “The actual contract amount of a time and materials contract may not exceed the estimated contract amount without written authorization from the buyer.”
(8)CA Business & Professions Code § 7159.10(e)(8) The heading: “Description of the Project and Materials to be Used and Equipment to be Installed” followed by a description of the project and materials to be used and equipment to be installed.
(9)CA Business & Professions Code § 7159.10(e)(9) The statement: “The law requires that the contractor offer you any parts that were replaced during the service call. If you do not want the parts, initial the checkbox labeled ‘OK for contractor to take replaced parts.’ ”
(10)CA Business & Professions Code § 7159.10(e)(10) A checkbox labeled “OK for contractor to take replaced parts.”
(11)CA Business & Professions Code § 7159.10(e)(11) If a service charge is charged, the heading “Amount of Service Charge” followed by the service charge, and the statement “You may be charged only one service charge, including any trip charge or inspection fee.”
(12)Copy CA Business & Professions Code § 7159.10(e)(12)
(A)Copy CA Business & Professions Code § 7159.10(e)(12)(A) (i) The contract, or an attachment to the contract as specified under subparagraph (C) of this paragraph, must include, in immediate proximity to the space reserved for the buyer’s signature, the following statement, in at least 12-point boldface type, which shall be dated and signed by the buyer:
“YOUR RIGHTS TO CANCEL BEFORE WORK BEGINS
(A)CA Business & Professions Code § 7159.10(A) You, the buyer, have the right to cancel this contract until:
1. You receive a copy of this contract signed and dated by you and the contractor; and
2. The contractor starts work.
(B)CA Business & Professions Code § 7159.10(B) However, even if the work has begun you, the buyer, may still cancel the contract for any of the reasons specified in items 1 through 4 of this paragraph. If any of these reasons occur, you may cancel the contract within three business days of signing the contract for normal service and repairs, or within seven business days of signing a contract to repair or correct conditions resulting from any sudden or catastrophic event for which a state of emergency has been declared by the President of the United States or the Governor, or for which a local emergency has been declared by the executive officer or governing body of any city, county, or city and county:
1. You may cancel the contract if the price, including all labor and materials, is more than seven hundred fifty dollars ($750).
2. You may cancel the contract if you did not initiate the contact with the contractor to request the work.
3. You may cancel the contract if the contractor sold you goods or services beyond those reasonably necessary to take care of the particular problem that caused you to contact the contractor.
4. You may cancel the contract if the payment was due or the contractor accepted any money before the work was complete.
(C)CA Business & Professions Code § 7159.10(C) If any of these reasons for canceling occurred, you may cancel the contract as specified under paragraph (B) above by e-mailing, mailing, faxing, or delivering a written notice to the contractor at the contractor’s place of business within three business days or, if applicable, seven business days of the date you received a signed and dated copy of this contract. Include your name, your address, and the date you received a signed copy of the contract and this notice.
If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under this contract. Or, you may, if you wish, comply with the contractor’s instructions on how to return the goods at the contractor’s expense and risk. If you make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.”
(ii)CA Business & Professions Code § 7159.10(ii) References to “three” in the statement set forth in clause (i) shall be changed to “five” for a buyer who is a senior citizen.
(iii)CA Business & Professions Code § 7159.10(iii) The five-day right to cancel added by the act that added clause (ii) to this subparagraph shall apply to contracts entered into on or after January 1, 2021.
(B)CA Business & Professions Code § 7159.10(B) This paragraph does not apply to home improvement contracts entered into by a person who holds an alarm company operator’s license issued pursuant to Chapter 11.6 (commencing with Section 7590), provided the person complies with Sections 1689.5, 1689.6, and 1689.7 of the Civil Code, as applicable.
(C)CA Business & Professions Code § 7159.10(C) The notice required in this paragraph may be incorporated as an attachment to the contract if the contract includes a checkbox and whichever statement is relevant in at least 12-point boldface type:
(i)CA Business & Professions Code § 7159.10(C)(i) “The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a ‘Notice of Your Right to Cancel.’ ”
(ii)CA Business & Professions Code § 7159.10(C)(ii) “The law requires that the contractor give you a notice explaining your right to cancel contracts for the repair or restoration of residential premises damaged by a disaster. Initial the checkbox if the contractor has given you a ‘Notice of Your Right to Cancel.’ ”
(f)CA Business & Professions Code § 7159.10(f) A bona fide service repairperson employed by a licensed contractor or subcontractor hired by a licensed contractor may enter into a service and repair contract on behalf of that contractor.
(g)CA Business & Professions Code § 7159.10(g) The provisions of this section are not exclusive and do not relieve the contractor from compliance with any other applicable provision of law.

Section § 7159.11

Explanation

If a licensed contractor or someone who should be licensed breaks any rules in Section 7159.10, they can be disciplined. This also applies to their agents or salespeople.

A violation of any provision of Section 7159.10 by a licensee, or a person subject to be licensed under this chapter, or by his or her agent or salesperson, is cause for discipline.

Section § 7159.14

Explanation

This law sets rules for service and repair contracts that cost up to $750. It requires contracts to be in writing and include all costs except finance charges. If a contract uses a time and materials basis, the final amount can't exceed the estimate without written consent from the buyer. Buyers must initiate contact for the repair, and contractors shouldn't upsell unnecessary items. Payment is due only after job completion, and only one service charge is allowed, which must be disclosed in ads. Contractors must offer replaced parts to customers and provide lien waivers upon payment. Violating some of these rules can lead to fines or jail. For fraud related to natural disasters, courts can order repayment based on one's ability to pay and impose fines. The statute is enforceable from July 2021.

(a)CA Business & Professions Code § 7159.14(a) This section applies to a service and repair contract as defined in Section 7159.10. A violation of this section by a licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, is cause for discipline.
(1)CA Business & Professions Code § 7159.14(a)(1) The contract shall not exceed seven hundred fifty dollars ($750).
(2)CA Business & Professions Code § 7159.14(a)(2) The contract shall be in writing and shall state the agreed contract amount, which may be stated as either a fixed contract amount in dollars and cents or, if a time and materials formula is used, as an estimated contract amount in dollars and cents.
(3)CA Business & Professions Code § 7159.14(a)(3) The contract amount shall include the entire cost of the contract including profit, labor, and materials, but excluding finance charges.
(4)CA Business & Professions Code § 7159.14(a)(4) The actual contract amount of a time and materials contract may not exceed the estimated contract amount without written authorization from the buyer.
(5)CA Business & Professions Code § 7159.14(a)(5) The prospective buyer shall have initiated contact with the contractor to request work.
(6)CA Business & Professions Code § 7159.14(a)(6) The contractor shall not sell the buyer goods or services beyond those reasonably necessary to take care of the particular problem that caused the buyer to contact the contractor.
(7)CA Business & Professions Code § 7159.14(a)(7) Payment shall not be due before the project is completed.
(8)CA Business & Professions Code § 7159.14(a)(8) A service and repair contractor shall charge only one service charge. For purposes of this chapter, a service charge includes charges such as a service or trip charge, or an inspection fee.
(9)CA Business & Professions Code § 7159.14(a)(9) A service and repair contractor charging a service charge shall disclose in all advertisements that there is a service charge and, when the customer initiates the call for service, shall disclose the amount of the service charge.
(10)CA Business & Professions Code § 7159.14(a)(10) The service and repair contractor shall offer to the customer any parts that were replaced.
(11)CA Business & Professions Code § 7159.14(a)(11) Upon any payment by the buyer, the contractor shall, if requested, obtain and furnish to the buyer a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for any portion of the work for which payment has been made.
(b)CA Business & Professions Code § 7159.14(b) A violation of paragraph (1), (2), (3), (4), (5), (6), or (8) of subdivision (a) by a licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, is a misdemeanor punishable by a fine of not less than one hundred dollars ($100) nor more than five thousand dollars ($5,000), or by imprisonment in a county jail not exceeding one year, or by both that fine and imprisonment.
(1)CA Business & Professions Code § 7159.14(b)(1) An indictment or information against a person who is not licensed but who is required to be licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (4) of subdivision (d) of Section 802 of the Penal Code, within four years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.
(2)CA Business & Professions Code § 7159.14(b)(2) An indictment or information against a person who is licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (2) of subdivision (d) of Section 802 of the Penal Code, within two years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.
(3)CA Business & Professions Code § 7159.14(b)(3) The limitations on actions in this subdivision do not apply to any administrative action filed against a licensed contractor.
(c)Copy CA Business & Professions Code § 7159.14(c)
(1)Copy CA Business & Professions Code § 7159.14(c)(1) Any person who violates this section as part of a plan or scheme to defraud an owner or tenant of a residential or nonresidential structure, including a mobilehome or manufactured home, in connection with the offer or performance of repairs to the structure for damage caused by a natural disaster, shall be ordered by the court to make full restitution to the victim based on the person’s ability to pay, defined as the overall capability of the defendant to reimburse the costs, or a portion of the costs, including consideration of, but not limited to, all of the following:
(A)CA Business & Professions Code § 7159.14(c)(1)(A) The defendant’s present financial position.
(B)CA Business & Professions Code § 7159.14(c)(1)(B) The defendant’s reasonably discernible future financial position, provided that the court shall not consider a period of more than one year from the date of the hearing for purposes of determining the reasonably discernible future financial position of the defendant.
(C)CA Business & Professions Code § 7159.14(c)(1)(C) The likelihood that the defendant will be able to obtain employment within one year from the date of the hearing.
(D)CA Business & Professions Code § 7159.14(c)(1)(D) Any other factor that may bear upon the defendant’s financial capability to reimburse the county for costs.
(2)CA Business & Professions Code § 7159.14(c)(2) In addition to full restitution, and imprisonment authorized by this section, the court may impose a fine of not less than five hundred dollars ($500) nor more than twenty-five thousand dollars ($25,000), based upon the defendant’s ability to pay. This subdivision applies to natural disasters for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code, or for which an emergency or major disaster is declared by the President of the United States.
(d)CA Business & Professions Code § 7159.14(d) This section shall become operative July 1, 2021.

Section § 7159.2

Explanation

This law deals with how payments are handled for home improvement contracts. If the contract is $5,000 or less, it cannot secure interest in real property, except for mechanic's liens or legal liens. For contracts over $5,000 funded by a mortgage loan, payments to the contractor must be done either by a check made out to both borrower and contractor, or through a third-party escrow agent if the borrower agrees. Violating this law can lead to paying actual damages or even triple the contract price if done intentionally. Seniors or disabled individuals can get up to an extra $5,000 in damages. Winning plaintiffs get court costs and attorney's fees, and defendants might, too, if the case was brought in bad faith.

(a)CA Business & Professions Code § 7159.2(a) No home improvement goods or services contract of a value of five thousand dollars ($5,000) or less shall provide for a security interest in real property, except for a mechanic’s lien or other interest in property that arises by operation of law. Any lien in violation of this subdivision is void and unenforceable.
(b)CA Business & Professions Code § 7159.2(b) When the proceeds of a loan secured by a mortgage on real property are used to fund goods or services pursuant to a home improvement goods or services contract of more than five thousand dollars ($5,000), the person or entity making the loan shall only pay a contractor under the home improvement goods or services contract from the proceeds of the loan by either of the following methods:
(1)CA Business & Professions Code § 7159.2(b)(1) By an instrument payable to the borrower or jointly to the borrower and the contractor.
(2)CA Business & Professions Code § 7159.2(b)(2) At the election of the borrower, through a third-party escrow agent pursuant to the terms of a written agreement signed by the borrower, the person or entity making the loan, and the contractor prior to the disbursement.
(c)CA Business & Professions Code § 7159.2(c) Any person or entity who violates any provision of this section shall be liable for actual damages suffered by the borrower for damages that proximately result from the violation.
(d)CA Business & Professions Code § 7159.2(d) Any person or entity who intentionally or as a pattern or practice violates any provision of this section shall be additionally liable for three times the contract price for the home improvement.
(e)CA Business & Professions Code § 7159.2(e) Any person who is a senior citizen or disabled person, as defined in subdivisions (f) and (g) of Section 1761 of the Civil Code, as part of any action for a violation of this section, may seek and be awarded, in addition to the remedies provided in this section, up to five thousand dollars ($5,000) as provided in subdivision (b) of Section 1780 of the Civil Code.
(f)CA Business & Professions Code § 7159.2(f) The court shall award court costs and attorney’s fees to a prevailing plaintiff in an action brought pursuant to this section. Reasonable attorney’s fees may be awarded to a prevailing defendant upon a finding by the court that the plaintiff’s prosecution of the action was not in good faith.

Section § 7159.5

Explanation

This law outlines rules for home improvement contracts involving licensed contractors in California. Contracts must be in writing and detail costs, including labor and materials, excluding finance charges. Any downpayment cannot exceed $1,000 or 10% of the contract, whichever is less. Payments must correspond to work completed, and contractors cannot demand payments exceeding the value of completed work. If requested, contractors must provide a release from any potential lien claims before receiving further payment. Special rules apply if a bond is provided, offering exemptions to certain payment restrictions. Violations can lead to fines or jail time, especially in areas affected by natural disasters, and must be legally addressed within specific time frames. Additionally, deliberate schemes to defraud in disaster situations must be compensated by the offender, who may also face fines and imprisonment.

This section applies to all home improvement contracts, as defined in Section 7151.2, between an owner or tenant and a contractor, whether a general contractor or a specialty contractor, that is licensed or subject to be licensed pursuant to this chapter with regard to the transaction.
(a)CA Business & Professions Code § 7159.5(a) Failure by the licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, to comply with the following provisions is cause for discipline:
(1)CA Business & Professions Code § 7159.5(a)(1) The contract shall be in writing and shall include the agreed contract amount in dollars and cents. The contract amount shall include the entire cost of the contract, including profit, labor, and materials, but excluding finance charges.
(2)CA Business & Professions Code § 7159.5(a)(2) If there is a separate finance charge between the contractor and the person contracting for home improvement, the finance charge shall be set out separately from the contract amount.
(3)CA Business & Professions Code § 7159.5(a)(3) If a downpayment will be charged, the downpayment shall not exceed one thousand dollars ($1,000) or 10 percent of the contract amount, whichever amount is less.
(4)CA Business & Professions Code § 7159.5(a)(4) If, in addition to a downpayment, the contract provides for payments to be made prior to completion of the work, the contract shall include a schedule of payments in dollars and cents specifically referencing the amount of work or services to be performed and any materials and equipment to be supplied.
(5)CA Business & Professions Code § 7159.5(a)(5) Except for a downpayment, the contractor shall neither request nor accept payment that exceeds the value of the work performed or material delivered. The prohibition prescribed by this paragraph extends to advance payment in whole or in part from any lender or financier for the performance or sale of home improvement goods or services.
(6)CA Business & Professions Code § 7159.5(a)(6) Upon any payment by the person contracting for home improvement, and prior to any further payment being made, the contractor shall, if requested, obtain and furnish to the person a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for any portion of the work for which payment has been made. The person contracting for home improvement may withhold all further payments until these releases are furnished.
(7)CA Business & Professions Code § 7159.5(a)(7) If the contract provides for a payment of a salesperson’s commission out of the contract price, that payment shall be made on a pro rata basis in proportion to the schedule of payments made to the contractor by the disbursing party in accordance with paragraph (4).
(8)CA Business & Professions Code § 7159.5(a)(8) A contractor furnishing a performance and payment bond, lien and completion bond, or a bond equivalent or joint control approved by the registrar covering full performance and payment is exempt from paragraphs (3), (4), and (5), and need not include, as part of the contract, the statement regarding the downpayment specified in subparagraph (C) of paragraph (8) of subdivision (d) of Section 7159, the details and statement regarding progress payments specified in paragraph (9) of subdivision (d) of Section 7159, or the Mechanics Lien Warning specified in paragraph (4) of subdivision (e) of Section 7159. A contractor furnishing these bonds, bond equivalents, or a joint control approved by the registrar may accept payment prior to completion. If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control. Notwithstanding any other law, a licensee shall be licensed in this state in an active status for not less than two years prior to submitting an Application for Approval of Blanket Performance and Payment Bond as provided in Section 858.2 of Title 16 of the California Code of Regulations as it read on January 1, 2016.
(b)Copy CA Business & Professions Code § 7159.5(b)
(1)Copy CA Business & Professions Code § 7159.5(b)(1) A violation of paragraph (1), (3), or (5) of subdivision (a) by a licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, is a misdemeanor punishable by a fine of not less than one hundred dollars ($100) nor more than five thousand dollars ($5,000), or by imprisonment in a county jail not exceeding one year, or by both that fine and imprisonment. If a violation occurs in a location damaged by a natural disaster for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code or for which an emergency or major disaster is declared by the President of the United States, the court shall impose the maximum fine.
(2)Copy CA Business & Professions Code § 7159.5(b)(2)
(A)Copy CA Business & Professions Code § 7159.5(b)(2)(A) An indictment or information against a person who is not licensed but who is required to be licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (4) of subdivision (d) of Section 802 of the Penal Code, within four years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.
(B)CA Business & Professions Code § 7159.5(b)(2)(A)(B) An indictment or information against a person who is licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (2) of subdivision (d) of Section 802 of the Penal Code, within two years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.
(C)CA Business & Professions Code § 7159.5(b)(2)(A)(C) The limitations on actions in this subdivision shall not apply to any administrative action filed against a licensed contractor.
(c)Copy CA Business & Professions Code § 7159.5(c)
(1)Copy CA Business & Professions Code § 7159.5(c)(1) Any person who violates this section as part of a plan or scheme to defraud an owner or tenant of a residential or nonresidential structure, including a mobilehome or manufactured home, in connection with the offer or performance of repairs to the structure for damage caused by a natural disaster, shall be ordered by the court to make full restitution to the victim based on the person’s ability to pay, defined as the overall capability of the defendant to reimburse the costs, or a portion of the costs, including consideration of, but not limited to, all of the following:
(A)CA Business & Professions Code § 7159.5(c)(1)(A) The defendant’s present financial position.
(B)CA Business & Professions Code § 7159.5(c)(1)(B) The defendant’s reasonably discernible future financial position, provided that the court shall not consider a period of more than one year from the date of the hearing for purposes of determining the reasonably discernible future financial position of the defendant.
(C)CA Business & Professions Code § 7159.5(c)(1)(C) The likelihood that the defendant will be able to obtain employment within one year from the date of the hearing.
(D)CA Business & Professions Code § 7159.5(c)(1)(D) Any other factor that may bear upon the defendant’s financial capability to reimburse the county for costs.
(2)CA Business & Professions Code § 7159.5(c)(2) In addition to full restitution, and imprisonment authorized by this section, the court may impose a fine of not less than five hundred dollars ($500) nor more than twenty-five thousand dollars ($25,000), based upon the defendant’s ability to pay. This subdivision applies to natural disasters for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code, or for which an emergency or major disaster is declared by the President of the United States.
(d)CA Business & Professions Code § 7159.5(d) This section shall become operative on July 1, 2021.

Section § 7159.6

Explanation

This law states that if there's extra work or changes to a construction contract, these changes are not valid unless they clearly describe the work, state the price difference, and detail how it affects payment schedules or deadlines. Contractors can't be forced to do additional work without written approval. If these rules aren't followed, a contractor can still get paid through other legal means to prevent unfair situations. These rules began on January 1, 2006.

(a)CA Business & Professions Code § 7159.6(a) An extra work or change order is not enforceable against a buyer unless the change order sets forth all of the following:
(1)CA Business & Professions Code § 7159.6(a)(1) The scope of work encompassed by the order.
(2)CA Business & Professions Code § 7159.6(a)(2) The amount to be added or subtracted from the contract.
(3)CA Business & Professions Code § 7159.6(a)(3) The effect the order will make in the progress payments or the completion date.
(b)CA Business & Professions Code § 7159.6(b) The buyer may not require a contractor to perform extra or change-order work without providing written authorization.
(c)CA Business & Professions Code § 7159.6(c) Failure to comply with the requirements of this section does not preclude the recovery of compensation for work performed based upon legal or equitable remedies designed to prevent unjust enrichment.
(d)CA Business & Professions Code § 7159.6(d) This section shall become operative on January 1, 2006.

Section § 7159.9

Explanation

This section explains that certain rules don't apply when selling and installing fire alarm systems if specific conditions are met. The contractor must follow rules in other sections, ensure the fire alarm services cost less than $500, and certify this amount. The contract must include the residence address and the contractor's details. Copies of these documents must be given to the client and kept for five years. If the contracting board asks for these documents, the contractor must provide them within 30 days, or risk disciplinary action.

(a)CA Business & Professions Code § 7159.9(a) Section 7159 does not apply to the sale, installation, and servicing of a fire alarm sold in conjunction with an alarm system, as defined in Section 7590.1 of the Alarm Company Act (Chapter 11.6 (commencing with Section 7590)), provided the licensee does all of the following:
(1)CA Business & Professions Code § 7159.9(a)(1) Complies with the contract requirements set forth in Section 7599.54.
(2)CA Business & Professions Code § 7159.9(a)(2) Complies with Sections 1689.5, 1689.6, and 1689.7 of the Civil Code, as applicable.
(3)CA Business & Professions Code § 7159.9(a)(3) Executes the following certification statement in the contract or in a separate certification document signed by all parties to the contract:
“All costs attributable to making the fire alarm system operable for the residence identified by this document, including sale and installation costs, do not exceed five hundred dollars ($500).”
(4)CA Business & Professions Code § 7159.9(4) Certifies to the following if the certification statement described in paragraph (3) is in a separate document:
“I certify that all statements and representations made by me in this document are true and accurate.”
(b)CA Business & Professions Code § 7159.9(b) The contract or separate certification document shall also include both of the following:
(1)CA Business & Professions Code § 7159.9(b)(1) The physical address of the residence for which the certification is applicable.
(2)CA Business & Professions Code § 7159.9(b)(2) The name, business address, and license number of the contractor as contained in the official records of the board.
(c)CA Business & Professions Code § 7159.9(c) The licensee shall give an exact copy of all documents required pursuant to this section to the party who is contracting to have the alarm system installed.
(d)CA Business & Professions Code § 7159.9(d) All documents required pursuant to this section shall be retained by the licensee for a period of five years in accordance with the provisions of Section 7111, and shall be made available to the board within 30 days of a written request.
(e)CA Business & Professions Code § 7159.9(e) Failure by the contractor to provide the board with the certification or contract within 30 days of a written request is cause for discipline.
(f)CA Business & Professions Code § 7159.9(f) Failure by the licensee to provide the board with the certification or contract within 30 days of a written request creates a presumption that the licensee has violated the provisions of Section 7159, unless evidence to the contrary is presented within the timeframe specified by the board.

Section § 7160

Explanation

If someone is tricked into signing a contract for an improvement project, like a home renovation, because of lies or false promises knowingly made by a contractor or salesperson, they can sue to get $500, plus their lawyer's fees, and any other damages they suffered because of these lies.

Any person who is induced to contract for a work of improvement, including but not limited to a home improvement, in reliance on false or fraudulent representations or false statements knowingly made, may sue and recover from such contractor or solicitor a penalty of five hundred dollars ($500), plus reasonable attorney’s fees, in addition to any damages sustained by him by reason of such statements or representations made by the contractor or solicitor.

Section § 7161

Explanation

This law makes it a misdemeanor for someone to engage in certain deceptive practices when it comes to home improvement contracts. It includes actions like using misleading ads, making false promises to get contracts, altering contract documents, or inflating financial obligations. Publishing false advertising about home improvements is also illegal. If these deceptive actions are part of a scheme to defraud property owners, especially after a natural disaster, the person responsible can be ordered to pay back the victim, taking into account their financial ability. The law also allows for fines up to $25,000. This is particularly relevant when a state of emergency is declared.

It is a misdemeanor for any person to engage in any of the following acts, the commission of which is cause for disciplinary action against any licensee or applicant:
(a)CA Business & Professions Code § 7161(a) Using false, misleading, or deceptive advertising as an inducement to enter into any contract for a work of improvement, including, but not limited to, any home improvement contract, whereby any member of the public may be misled or injured.
(b)CA Business & Professions Code § 7161(b) Making any substantial misrepresentation in the procurement of a contract for a home improvement or other work of improvement or making any false promise of a character likely to influence, persuade, or induce any person to enter into the contract.
(c)CA Business & Professions Code § 7161(c) Any fraud in the execution of, or in the material alteration of, any contract, trust deed, mortgage, promissory note, or other document incident to a home improvement transaction or other transaction involving a work of improvement.
(d)CA Business & Professions Code § 7161(d) Preparing or accepting any trust deed, mortgage, promissory note, or other evidence of indebtedness upon the obligations of a home improvement transaction or other transaction for a work of improvement with knowledge that it specifies a greater monetary obligation than the consideration for the improvement work, which consideration may be a time sale price.
(e)CA Business & Professions Code § 7161(e) Directly or indirectly publishing any advertisement relating to home improvements or other works of improvement that contains an assertion, representation, or statement of fact that is false, deceptive, or misleading, or by any means advertising or purporting to offer to the general public this improvement work with the intent not to accept contracts for the particular work or at the price that is advertised or offered to the public, except that any advertisement that is subject to and complies with the existing rules, regulations, or guides of the Federal Trade Commission shall not be deemed false, deceptive, or misleading.
(f)Copy CA Business & Professions Code § 7161(f)
(1)Copy CA Business & Professions Code § 7161(f)(1) Any person who violates subdivision (b), (c), (d), or (e) as part of a plan or scheme to defraud an owner of a residential or nonresidential structure, including a mobilehome or manufactured home, in connection with the offer or performance of repairs to the structure for damage caused by a natural disaster, shall be ordered by the court to make full restitution to the victim based on the person’s ability to pay, defined as the overall capability of the defendant to reimburse the costs, or a portion of the costs, including consideration of, but not limited to, all of the following:
(A)CA Business & Professions Code § 7161(f)(1)(A) The defendant’s present financial position.
(B)CA Business & Professions Code § 7161(f)(1)(B) The defendant’s reasonably discernible future financial position, provided that the court shall not consider a period of more than one year from the date of the hearing for purposes of determining the reasonably discernible future financial position of the defendant.
(C)CA Business & Professions Code § 7161(f)(1)(C) The likelihood that the defendant will be able to obtain employment within one year from the date of the hearing.
(D)CA Business & Professions Code § 7161(f)(1)(D) Any other factor that may bear upon the defendant’s financial capability to reimburse the county for costs.
(2)CA Business & Professions Code § 7161(f)(2) In addition to full restitution and imprisonment as authorized by this section, the court may impose a fine of not less than five hundred dollars ($500) nor more than twenty-five thousand dollars ($25,000), based upon the defendant’s ability to pay. This subdivision applies to natural disasters for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code or for which an emergency or major disaster is declared by the President of the United States.
(g)CA Business & Professions Code § 7161(g) This section shall become operative on July 1, 2021.

Section § 7162

Explanation

This law states that if someone licensed to do home improvements in California makes claims about specific brands, qualities, or sizes of items like appliances or fixtures, these details must be clearly described in the written contract. If they fail to install the specified items, they can face disciplinary actions.

(a)CA Business & Professions Code § 7162(a) Notwithstanding any other provision of law, any representation by a person licensed pursuant to this chapter with respect to a trademark or brand name, quality, or size of any goods or materials, in reference to bathroom fixtures, a sink, stove, refrigerator, lighting, carpeting and other floor surfaces, burglar and smoke alarms, a solar energy system, paints, textured coatings, siding and other wall surfaces, insulation, roofing, air conditioning and heating systems, and appliances, to be provided by the person pursuant to a home improvement contract, as defined in Section 7151.2, shall set forth, in writing, in the contract or specifications and shall include a description of the goods or materials, including any brand name, model number, or similar designation.
(b)CA Business & Professions Code § 7162(b) Failure to install the specific goods or materials as represented as required by this section constitutes a cause for disciplinary action under this chapter.

Section § 7163

Explanation

This law says that a home improvement contract can't be enforced if getting a loan is part of the deal, unless a few conditions are met. These include the loan being approved by a third party, the buyer agreeing to the loan, and the buyer not canceling the loan as per the federal Truth in Lending Act. The contractor can’t start work or make claims about the contract being valid until these steps are completed. If the contract isn’t valid, the contractor must return all money or property to the buyer. Although homeowners are generally not obligated to return services or items received, they must return items if it's practical and the contractor meets certain conditions. Lastly, any waiver of these rules is void unless it's an emergency repair scenario.

(a)CA Business & Professions Code § 7163(a) No contract for home improvement shall be enforceable against the buyer if the obtaining of a loan for all or a portion of the contract price is a condition precedent to the contract or if the contractor provides financing, or in any manner assists the buyer to obtain a loan or refers the buyer to any person who may loan or arrange a loan for all or a portion of the contract price unless all of the following requirements are satisfied:
(1)CA Business & Professions Code § 7163(a)(1) The third party, if any, agrees to make the loan.
(2)CA Business & Professions Code § 7163(a)(2) The buyer agrees to accept the loan or financing.
(3)CA Business & Professions Code § 7163(a)(3) The buyer does not rescind the loan or financing transaction, within the period prescribed for rescission, pursuant to the federal Truth in Lending Act (15 U.S.C. Sec. 1601 et seq.) or Regulation Z, if applicable.
(b)CA Business & Professions Code § 7163(b) Until the requirements of paragraphs (1), (2), and (3) of subdivision (a) are satisfied, it shall be unlawful for the contractor to do any of the following:
(1)CA Business & Professions Code § 7163(b)(1) Deliver any property or perform any services other than obtaining building permits or other similar services preliminary to the commencement of the home improvement for which no mechanic’s lien can be claimed.
(2)CA Business & Professions Code § 7163(b)(2) Represent in any manner that the contract is enforceable or that the buyer has any obligation thereunder.
Any violation of this subdivision shall render the contract unenforceable.
(c)CA Business & Professions Code § 7163(c) If the contract is unenforceable pursuant to subdivision (a) or subdivision (b), the contractor shall immediately and without condition return all money, property, and other consideration given by the buyer. If the buyer gave any property as consideration and the contractor does not or cannot return it for whatever reason, the contractor shall immediately return the fair market value of the property or its value as designated in the contract, whichever is greater. Nothing herein shall prohibit a contractor from receiving a downpayment otherwise permitted by law provided the contractor returns the downpayment as herein required if the contract is unenforceable pursuant to subdivision (a) or (b).
(d)Copy CA Business & Professions Code § 7163(d)
(1)Copy CA Business & Professions Code § 7163(d)(1) Except as provided in paragraph (2), the buyer may retain without obligation in law or equity any services or property provided pursuant to a contract that is unenforceable pursuant to subdivision (a) or subdivision (b).
(2)CA Business & Professions Code § 7163(d)(2) If the contractor has delivered any property to the buyer pursuant to a contract which is unenforceable pursuant to subdivision (a) or subdivision (b), the buyer shall make the property available to the contractor for return provided that all of the following requirements are satisfied:
(A)CA Business & Professions Code § 7163(d)(2)(A) The property can be practically returned to the contractor without causing any damage to the buyer.
(B)CA Business & Professions Code § 7163(d)(2)(B) The contractor, at the contractor’s expense, first returns to the buyer any money, property, and other consideration taken by the contractor provided that the property is returned in the condition that it was in immediately prior to its taking. If applicable, the contractor shall also, at its expense, reinstall any property taken in the manner in which the property had been installed prior to its taking.
(C)CA Business & Professions Code § 7163(d)(2)(C) The contractor, at the contractor’s expense, picks up the property within 60 days of the execution of the contract.
(e)CA Business & Professions Code § 7163(e) For the purpose of this section, “home improvement” means “home improvement” as defined in Section 7151. Goods are included within the definition notwithstanding whether they are to be attached to real property or to be so affixed to real property as to become a part thereof whether or not severable therefrom.
(f)CA Business & Professions Code § 7163(f) The rights and remedies provided the buyer under this section are nonexclusive and cumulative to all other rights and remedies under other laws.
(g)CA Business & Professions Code § 7163(g) Any waiver of this section shall be deemed contrary to public policy and shall be void and unenforceable. However, the buyer may waive subdivisions (a) and (b) to the extent that the contract is executed in connection with the making of emergency repairs or services that are necessary for the immediate protection of persons or real or personal property. The buyer’s waiver for emergency repairs or services shall be in a dated written statement that describes the emergency, states that the contractor has informed the buyer of subdivisions (a) and (b) and that the buyer waives those provisions, and is signed by each owner of the property. Waivers made on printed forms are void and unenforceable.

Section § 7164

Explanation

If you're hiring a contractor to build a single-family home that you'll live in for at least a year, the contract has to be in writing and signed by both you and the contractor. This written contract must include key details: the contractor's information, when the work will start and end, and a legal description of the property. It should also include a warning about mechanics liens, which can happen if someone who worked on your home isn't paid. This lien can be a serious issue, potentially leading to you paying twice or losing your home. Therefore, the law encourages homeowners to check the contractor's general liability insurance. The contract should also inform you that you might need to pay for a performance bond, which is extra financial security for the work. All of this became mandatory in 2006.

(a)CA Business & Professions Code § 7164(a) Notwithstanding Section 7044, every contract and any changes in a contract, between an owner and a contractor, for the construction of a single-family dwelling to be retained by the owner for at least one year shall be evidenced in writing signed by both parties.
(b)CA Business & Professions Code § 7164(b) The writing shall contain the following:
(1)CA Business & Professions Code § 7164(b)(1) The name, address, and license number of the contractor.
(2)CA Business & Professions Code § 7164(b)(2) The approximate dates when the work will begin and be substantially completed.
(3)CA Business & Professions Code § 7164(b)(3) A legal description of the location where the work will be done.
(4)CA Business & Professions Code § 7164(b)(4) A statement with the heading “Mechanics Lien Warning” as follows:
“MECHANICS LIEN WARNING:
Anyone who helps improve your property, but who is not paid, may record what is called a mechanics lien on your property. A mechanics lien is a claim, like a mortgage or home equity loan, made against your property and recorded with the county recorder.
Even if you pay your contractor in full, unpaid subcontractors, suppliers, and laborers who helped to improve your property may record mechanics liens and sue you in court to foreclose the lien. If a court finds the lien is valid, you could be forced to pay twice or have a court officer sell your home to pay the lien. Liens can also affect your credit.
To preserve their right to record a lien, each subcontractor and material supplier must provide you with a document called a ‘Preliminary Notice.’ This notice is not a lien. The purpose of the notice is to let you know that the person who sends you the notice has the right to record a lien on your property if he or she is not paid.
BE CAREFUL.  The Preliminary Notice can be sent up to 20 days after the subcontractor starts work or the supplier provides material. This can be a big problem if you pay your contractor before you have received the Preliminary Notices.
You will not get Preliminary Notices from your prime contractor or other persons you contract with directly or from laborers who work on your project. The law assumes that you already know they are improving your property.
PROTECT YOURSELF FROM LIENS.  You can protect yourself from liens by getting a list from your contractor of all the subcontractors and material suppliers that work on your project. Find out from your contractor when these subcontractors started work and when these suppliers delivered goods or materials. Then wait 20 days, paying attention to the Preliminary Notices you receive.
PAY WITH JOINT CHECKS.  One way to protect yourself is to pay with a joint check. When your contractor tells you it is time to pay for the work of a subcontractor or supplier who has provided you with a Preliminary Notice, write a joint check payable to both the contractor and the subcontractor or material supplier.
For other ways to prevent liens, visit CSLB’s Web site at www.cslb.ca.gov or call CSLB at 800-321-CSLB (2752).
REMEMBER, IF YOU DO NOTHING, YOU RISK HAVING A LIEN PLACED ON YOUR HOME.  This can mean that you may have to pay twice, or face the forced sale of your home to pay what you owe.”
(5)Copy CA Business & Professions Code § 7164(5)
(A)Copy CA Business & Professions Code § 7164(5)(A) A statement prepared by the board through regulation that emphasizes the value of commercial general liability insurance and encourages the owner to verify the contractor’s insurance coverage and status.
(B)CA Business & Professions Code § 7164(5)(A)(B) A check box indicating whether or not the contractor carries commercial general liability insurance, and if that is the case, the name and the telephone number of the insurer.
(c)CA Business & Professions Code § 7164(c) The writing may also contain other matters agreed to by the parties to the contract. The writing shall be legible and shall clearly describe any other document which is to be incorporated into the contract. Prior to commencement of any work, the owner shall be furnished a copy of the written agreement, signed by the contractor. The provisions of this section are not exclusive and do not relieve the contractor from compliance with all other applicable provisions of law.
(d)CA Business & Professions Code § 7164(d) Every contract subject to the provisions of this section shall contain, in close proximity to the signatures of the owner and contractor, a notice in at least 10-point boldface type or in all capital letters, stating that the owner has the right to require the contractor to have a performance and payment bond and that the expense of the bond may be borne by the owner.
(e)CA Business & Professions Code § 7164(e) The requirements in paragraph (5) of subdivision (b) shall become operative three months after the board adopts the regulations referenced in subparagraph (A) of paragraph (5) of subdivision (b).
(f)CA Business & Professions Code § 7164(f) This section shall become operative on January 1, 2006.

Section § 7165

Explanation

This section outlines alternative requirements for a swimming pool construction contract when it is financed by a third-party lender. If certain conditions are met, these requirements can replace parts of another section of the law. Key conditions include the lender agreeing in writing to finance the estimated construction cost and providing the loan terms as required by federal law. Additionally, the borrower must confirm in writing after three business days that construction can begin before the loan's cancellation period ends. The borrower must sign a separate document acknowledging these terms, and if they don't pay, the contractor may place a lien on the property. This law applies to all parties involved in the loan and construction of the swimming pool.

The requirements of this section may be substituted for the requirements of paragraphs (1), (2), and (3) of subdivision (a) of Section 7163 if a swimming pool contract is to be financed by a third-party lender and if all the following conditions are met:
(a)CA Business & Professions Code § 7165(a) The lender has agreed, in writing, to provide financing to the buyer for the maximum estimated construction cost of the swimming pool.
(b)CA Business & Professions Code § 7165(b) The lender has provided the buyer a written copy of the terms and conditions of the loan for the maximum estimated construction cost of the swimming pool, including the following terms disclosed in the manner required by the federal Truth in Lending Act and Regulation Z: the annual percentage rate, the finance charge, the amount financed, the total number of payments, the payment schedule, and a description of the security interest to be taken by the lender.
(c)CA Business & Professions Code § 7165(c) The lender has agreed in writing to the following:
(1)CA Business & Professions Code § 7165(c)(1) To offer to loan the maximum estimated construction cost on the terms and conditions disclosed pursuant to subdivision (b).
(2)CA Business & Professions Code § 7165(c)(2) If the construction cost of the swimming pool is determined after the completion of excavation to be less than the maximum estimated construction cost, to offer to loan the lesser amount needed to complete the construction of the swimming pool on the same security as, and at an annual percentage rate and monthly payment amount not to exceed, that disclosed in subdivision (b).
The lender’s written agreement shall state the duration of the offer, which shall not be less than 15 days following the completion of the excavation of the swimming pool.
(d)CA Business & Professions Code § 7165(d) The buyer acknowledges receipt of the writings required by subdivisions (a), (b), and (c) and, no sooner than three business days after receiving all of these writings, requests on the form prescribed in subdivision (e) that the contractor begin performance of the swimming pool contract prior to the expiration of any rescission period applicable to the loan.
(e)CA Business & Professions Code § 7165(e) The request of a buyer, described in subdivision (d), shall be set forth on a document separate and apart from the swimming pool contract and shall contain the following notice in at least 10-point type unless otherwise stated:
Under the law, this contract is not enforceable until:
(1)CA Business & Professions Code § 7165(1) A third party agrees to make a loan to finance the construction cost of the swimming pool;
(2)CA Business & Professions Code § 7165(2) You agree to accept the loan; and
(3)CA Business & Professions Code § 7165(3) You do not cancel the loan within the period prescribed for cancellation under the federal Truth in Lending Act or Regulation Z (usually three business days after the loan is consummated).
Until the cancellation period is over, the contractor cannot deliver any materials or perform any services except preliminary services for which no mechanic’s lien can be claimed.
However, as an alternative to the above, you can ask the contractor to start work and deliver materials before the cancellation period on the loan is over if all of the following have occurred:
(1)CA Business & Professions Code § 7165(1) The lender has agreed, in writing, to provide you with financing for up to the maximum estimated construction cost of the swimming pool.
(2)CA Business & Professions Code § 7165(2) The lender has provided you with a written copy of the terms and conditions of a loan for the maximum estimated cost, including the annual percentage rate, the finance charge, the amount financed, the total of payments, the payment schedule, and a description of the security interest to be taken by the lender.
(3)CA Business & Professions Code § 7165(3) The lender has agreed in writing to offer these terms and conditions for a period not less than 15 days following completion of the excavation of the swimming pool.
(4)CA Business & Professions Code § 7165(4) Three business days have passed since you received the writing mentioned in paragraphs (1), (2), and (3), and you then sign a copy of this form to request that the contractor begin construction of the swimming pool before the cancellation period on your loan is over.
The first day you can sign the request for the contractor to begin construction of the swimming pool is
.
(contractor to insert third business day after buyer receives writings described in subdivisions (a), (b), and (c))
If you sign this request, the contractor will be permitted to immediately begin performance of the contract, and if the contractor is not paid in accordance with the terms of the contract, he or she may file a lien against your property for the value of the labor and materials provided. [This paragraph shall be printed in 12-point type.]
I/we request that the contractor immediately start construction of the swimming pool.
______ Date __________ Buyer(s)”
(f)CA Business & Professions Code § 7165(f) The contractor shall provide the buyer a copy of the buyer’s signed request at the time of signature.
(g)CA Business & Professions Code § 7165(g) This section applies to each buyer who signs the swimming pool contract or the promissory note, other evidence of indebtedness, or security instrument incident to the loan for swimming pool construction.
(h)CA Business & Professions Code § 7165(h) For the purpose of this section, “business day” has the meaning provided in Section 9 of the Civil Code.

Section § 7166

Explanation

This law says that certain rules (specifically, the ones in Article 10) don't apply when building swimming pools meant for places other than just a single-family home. Also, if a contractor is building both the house and the pool as part of one project, those rules don't apply to the pool either.

The provisions of Article 10 shall not apply to contracts for the construction of swimming pools to be built for the use and enjoyment of other than a single-family unit upon or contiguous to premises occupied only by a single-family unit, nor shall they apply to the construction of swimming pools built as part of an original building plan by the same contractor who builds a single-family dwelling unit on the premises.

Section § 7167

Explanation

This law states that if a contract primarily for building a swimming pool doesn't follow certain requirements, it is considered void, meaning the contractor can't enforce it. However, even if the contractor fails to meet one specific requirement, they might still be able to get paid for the actual work they did through other legal approaches to prevent unfair gain by the client.

(a)CA Business & Professions Code § 7167(a) Any contract, the primary purpose of which is the construction of a swimming pool, that does not substantially comply with paragraph (4) or (5) of subdivision (c) or paragraph (7), (8), or (9) of subdivision (d) of Section 7159, shall be void and unenforceable by the contractor as contrary to public policy.
(b)CA Business & Professions Code § 7167(b) Failure by the contractor to comply with paragraph (5) of subdivision (c) of Section 7159 as set forth in subdivision (a) of this section does not preclude the recovery of compensation for work performed based on quasi-contract, quantum meruit, restitution, or other similar legal or equitable remedies designed to prevent unjust enrichment.

Section § 7168

Explanation

If you get into a legal dispute with a swimming pool contractor over a pool construction contract, the court will make the losing side pay for the winning side's reasonable attorney fees.

In any action between a person contracting for construction of a swimming pool and a swimming pool contractor arising out of a contract for swimming pool construction, the court shall award reasonable attorney’s fees to the prevailing party.

Section § 7169

Explanation

This law requires that anyone selling, leasing, or financing a solar energy system in California must provide a detailed disclosure document to consumers. It must include information about the cost, expected savings, financing options, consumer rights, and complaint procedures. On top of that, optional information like financing details, calculations for panel needs and output, and any related fees or impacts on home sales should also be made available. Importantly, contracts and disclosures must be in the same language as any marketing or sales presentation used. For systems using certain financing, a specific form might satisfy part of these requirements. The term 'solar energy system' here refers to specific systems used on homes. Lastly, the law does not cover systems pre-installed in new buildings.

(a)CA Business & Professions Code § 7169(a) The board, in collaboration with the Public Utilities Commission, shall develop and make available a “solar energy system disclosure document” or documents that provide a consumer, at a minimum, accurate, clear, and concise information regarding the installation of a solar energy system, total costs of installation, anticipated savings, the assumptions and inputs used to estimate the savings, and the implications of various financing options.
(b)CA Business & Professions Code § 7169(b) On or before July 1, 2018, the board, in collaboration with the Public Utilities Commission, shall develop, and make available on its internet website the disclosure document described in subdivision (a) that a solar energy system company shall provide to a consumer prior to completion of a sale, financing, or lease of a solar energy system. The “solar energy system disclosure document” shall be printed on the front page or cover page of every solar energy contract. The “solar energy system disclosure document” shall be printed in boldface 16-point type and include the following types of primary information:
(1)CA Business & Professions Code § 7169(b)(1) The total cost and payments for the system, including financing costs.
(2)CA Business & Professions Code § 7169(b)(2) Information on how and to whom customers may provide complaints.
(3)CA Business & Professions Code § 7169(b)(3) The consumer’s right to the applicable cancellation period pursuant to Section 7159 of the Business and Professions Code.
(c)CA Business & Professions Code § 7169(c) At the board’s discretion, other types of supporting information the board and the commission deem appropriate or useful in furthering the directive described in subdivision (a) may be included in the solar energy disclosure document following the front page or cover page, including, but not limited to:
(1)CA Business & Professions Code § 7169(c)(1) The amounts and sources of financing obtained.
(2)CA Business & Professions Code § 7169(c)(2) The calculations used by the home improvement salesperson to determine how many panels the homeowner needs to install.
(3)CA Business & Professions Code § 7169(c)(3) The calculations used by the home improvement salesperson to determine how much energy the panels will generate.
(4)CA Business & Professions Code § 7169(c)(4) Any additional monthly fees the homeowner’s electric company may bill, any turn-on charges, and any fees added for the use of an internet monitoring system of the panels or inverters.
(5)CA Business & Professions Code § 7169(c)(5) The terms and conditions of any guaranteed rebate.
(6)CA Business & Professions Code § 7169(c)(6) The final contract price, without the inclusion of possible rebates.
(7)CA Business & Professions Code § 7169(c)(7) The solar energy system company’s contractor’s license number.
(8)CA Business & Professions Code § 7169(c)(8) The impacts of solar energy system installations not performed to code.
(9)CA Business & Professions Code § 7169(c)(9) Types of solar energy system malfunctions.
(10)CA Business & Professions Code § 7169(c)(10) Information about the difference between a solar energy system lease and a solar energy system purchase.
(11)CA Business & Professions Code § 7169(c)(11) The impacts that the financing options, lease agreement terms, or contract terms will have on the sale of the consumer’s home, including any balloon payments or solar energy system relocation that may be required if the contract is not assigned to the new owner of the home.
(12)CA Business & Professions Code § 7169(c)(12) A calculator that calculates performance of solar projects to provide solar customers the solar power system’s projected output, which may include an expected performance-based buy-down calculator.
(d)CA Business & Professions Code § 7169(d) A contract for sale, financing, or lease of a solar energy system and the solar energy system disclosure document shall be written in the same language as was principally used in the oral sales presentation made to the consumer or the print or digital marketing material given to the consumer.
(e)CA Business & Professions Code § 7169(e) For solar energy systems utilizing Property Assessed Clean Energy (PACE) financing, the Financing Estimate and Disclosure form required by subdivision (b) of Section 5898.17 of the Streets and Highways Code shall satisfy the requirements of this section with respect to the financing contract only, but not, however, with respect to the underlying contract for installation of the solar energy system.
(f)CA Business & Professions Code § 7169(f) The board shall post the PACE Financing Estimate and Disclosure form required by subdivision (b) of Section 5898.17 of the Streets and Highways Code on its internet website.
(g)CA Business & Professions Code § 7169(g) For purposes of this section, “solar energy system” means a solar energy device to be installed on a residential building that has the primary purpose of providing for the collection and distribution of solar energy for the generation of electricity, that produces at least one kW, and not more than five MW, alternating current rated peak electricity, and that meets or exceeds the eligibility criteria established pursuant to Section 25782 of the Public Resources Code.
(h)CA Business & Professions Code § 7169(h) This section does not apply to a solar energy system that is installed as a standard feature on new construction.

Section § 7170

Explanation

This section requires the Contractors State License Board to handle complaints and questions about solar energy companies and contractors. Starting July 1, 2019, they must create a yearly report with details about these complaints, including the number and type of complaints, where they came from, and how they were resolved. This report must be accessible on their website and the Public Utilities Commission's site.

(a)CA Business & Professions Code § 7170(a) The Contractors State License Board shall receive and review complaints and consumer questions regarding solar energy systems companies and solar contractors. The board shall also receive complaints received from state agencies regarding solar energy systems companies and solar contractors.
(b)CA Business & Professions Code § 7170(b) Beginning on July 1, 2019, the board annually shall compile a report documenting consumer complaints relating to solar contractors. The report shall be made available publicly on the board’s and the Public Utilities Commission’s internet websites. The report shall contain all of the following:
(1)CA Business & Professions Code § 7170(b)(1) The number and types of complaints.
(2)CA Business & Professions Code § 7170(b)(2) The ZIP Code where the consumer complaint originated.
(3)CA Business & Professions Code § 7170(b)(3) The disposition of all complaints received against a solar contractor.